London Boroughs of Richmond and Wandsworth has published this notice through Delta eSourcing
Notice Summary |
---|
Title: | The Provision of Repair and Maintenance Works to Tenanted Properties (Central Area) |
Notice type: | Contract Award Notice |
Authority: | London Boroughs of Richmond and Wandsworth |
Nature of contract: | Services |
Procedure: | Open |
Short Description: | The aim of this procurement is to appoint a single service provider to act as primary contractor for the central area repairs tenanted contract to undertake 60% of the works by value, there is already an existing secondary contractor undertaking the remaining 40% of the works for the provision of the services.Repairs and maintenance works are to be carried out within defined priority timescale categories and Tenderers shall be invited to tender an Adjustment Percentage to the Detailed Rates set out at Schedule 2 to the draft Contract contained within Volume 2, to act as primary Contractor. |
Published: | 21/09/2020 13:20 |
View Full Notice
Section I: Contracting Authority
I.1) Name, Addresses and Contact Point(s):
Wandsworth Borough Council
Town Hall, Wandsworth High Street, London, SW18 2PU, United Kingdom
Tel. +44 2088716114, Email: valerie.kuijpers@richmondandwandsworth.gov.uk
Contact: Valerie Kuijpers
Main Address: https://www.delta-esourcing.com/, Address of the buyer profile: https://www.wandsworth.gov.uk
NUTS Code: UKI34
I.2) Joint procurement:
The contract involves joint procurement: No
In the case of joint procurement involving different countries, state applicable national procurement law: Not Provided
The contract is awarded by a central purchasing body: No
I.4)Type of the contracting authority:
Regional or local authority
I.5) Main activity:
General public services
Section II: Object Of The Contract
II.1) Scope of the procurement
II.1.1) Title: The Provision of Repair and Maintenance Works to Tenanted Properties (Central Area)
Reference number: Not Provided
II.1.2) Main CPV code:
50700000 - Repair and maintenance services of building installations.
II.1.3) Type of contract: SERVICES
II.1.4) Short description: The aim of this procurement is to appoint a single service provider to act as primary contractor for the central area repairs tenanted contract to undertake 60% of the works by value, there is already an existing secondary contractor undertaking the remaining 40% of the works for the provision of the services.Repairs and maintenance works are to be carried out within defined priority timescale categories and Tenderers shall be invited to tender an Adjustment Percentage to the Detailed Rates set out at Schedule 2 to the draft Contract contained within Volume 2, to act as primary Contractor.
II.1.6) Information about lots
This contract is divided into lots: No
II.1.7) Total value of the procurement (excluding VAT)
Value: 1,040
Currency:GBP
II.2) Description
II.2.2) Additional CPV code(s):
Not Provided
II.2.3) Place of performance
Nuts code:
UKI34 - Wandsworth
Main site or place of performance:
Wandsworth
II.2.4) Description of the procurement: The aim of this procurement is to appoint a single service provider to act as primary contractor for the central area repairs tenanted contract (area overview in Appendix 3 of Volume 2 - specification) to undertake 60% of the works by value, there is already an existing secondary contractor undertaking the remaining 40% of the works for the provision of the services.
II.2.5) Award criteria:
Cost criterion - Name: price / Weighting: 80
Cost criterion - Name: quality / Weighting: 20
II.2.11) Information about options
Options: No
II.2.13) Information about European Union funds
The procurement is related to a project and/or programme financed by European Union funds: No
II.2.14) Additional information: Not Provided
Section IV: Procedure
IV.1) Description
IV.1.1)Type of procedure: Open
IV.1.3) Information about a framework agreement or a dynamic purchasing system
The procurement involves the establishment of a framework agreement: No
IV.1.6) Information about electronic auction
An electronic auction has been used: No
IV.1.8) Information about the Government Procurement Agreement (GPA)
The procurement is covered by the Government Procurement Agreement: No
IV.2) Administrative information
IV.2.1) Previous publication concerning this procedure
Notice number in the OJEU: 2019/S 120-294258
IV.2.9) Information about termination of call for competition in the form of a prior information notice
The contracting authority will not award any further contracts based on the above prior information notice: No
Section V: Award of contract
Award Of Contract (No.1)
Contract No: CPT2248
Lot Number: Not Provided
Title: Not Provided
A contract/lot is awarded: Yes
V.2) Award of contract
V.2.1) Date of conclusion of the contract: 07/10/2019
V.2.2) Information about tenders
Number of tenders received: 7
Number of tenders received from SMEs: Not Provided
Number of tenders received from tenderers from other EU Member States: Not Provided
Number of tenders received from tenderers from non-EU Member States: Not Provided
Number of tenders received by electronic means: 7
V.2.3) Name and address of the contractor
The contract has been awarded to a group of economic operators: No
Contractor (No.1)
MNM Property Services Ltd, 03117531
97 Judd St, London, WC1H 9JG, United Kingdom
Tel. +44 2084381852
Internet address: https://mnm-properties.co.uk/
NUTS Code: UKI
The contractor is an SME: Yes
V.2.4) Information on value of the contract/lot (excluding VAT)
Initial estimated total value of the contract/lot: 1,119,800
Total value of the contract/lot: 1,119,800
Currency: GBP
V.2.5) Information about subcontracting
The contract is likely to be subcontracted: No
Section VI: Complementary information
VI.3) Additional information: The contracting authority considers that this contract may be suitable for economic operators that are small or medium enterprises (SMEs). However, any selection of tenderers will be based solely on the criteria set out for the procurement.
To view this notice, please click here:
https://www.delta-esourcing.com/delta/viewNotice.html?noticeId=447903988
VI.4) Procedures for review
VI.4.1) Review body
Royal Courts of Justice
The Strand, London, WC2A 2LL, United Kingdom
Tel. +44 2079476000
VI.4.2) Body responsible for mediation procedures
Cabinet Office
Whitehall, Westminster, London, SW1A 2AS, United Kingdom
Tel. +44 2072761234
VI.4.3) Review procedure
Precise information on deadline(s) for review procedures: The Council will incorporate a minimum 10 calendar day standstill period at the point where contract award is communicated to tenderers. Applicants who are unsuccessful shall be informed by the Council as soon aspossible after the decision has been made as to the reasons why the applicant was unsuccessful. If an appeal regarding the award of the contract has not been successfully resolved, The Public Contracts Regulations 2015(SI 2015 No. 102) provide for aggrieved parties who have been harmed or are at risk of harm by breach of the rules to take legal action. Any such action must be brought within the applicable limitation period. Where a contract has not been entered into, the court may order the setting aside of the award decision or order the authorities to amend any document and may award damages.
If the contract has been entered into the court may, depending on the circumstances, award damages, make a declaration of ineffectiveness, order the relevant authority to pay a fine, and/or order that the duration of thecontract be shortened. The purpose of the standstill period referred to above is to allow the parties to apply to the courts to set aside the award decision before the contract is entered into.
VI.4.4) Service from which information about the review procedure may be obtained
Cabinet Office
70 Whitehall, Westminster, London, SW1A 2AS, United Kingdom
Tel. +44 2072761234
VI.5) Date of dispatch of this notice: 21/09/2020